Section 1105.  Control of Work

 

1105.01     AUTHORITY OF ENGINEER.

 

A.    The Engineer will decide all questions which may arise as to the quality and acceptability of materials furnished and work performed and as to the rate of progress of the work, all disputed and mutual rights between contractor, all contract documents, and all questions as to the acceptable fulfillment of the contract on the part of the Contractor. The Engineer's decisions will be final.

 

B.    For authority to temporarily suspend work, see Articles 1105.06 and 1108.06.

 

1105.02     PLANS.

 

A.    The final plans on file in the office of the Contracting Authority, show the location, typical construction details, and dimensions of the work contemplated. The work shall be performed in conformity therewith, except in case of error or unforeseen contingency.

 

B.    The plans are made from careful surveys and represent the foreseen construction requirements. Any appreciable deviation from the plans made necessary to expedite construction, or because of error, shall be called to the attention of the other party, in writing, by the party discovering such conditions. If necessary, revised plans will be provided.

 

1105.03     WORKING DRAWINGS.

 

A.    The plans will shall be supplemented by such working drawings as are necessary to adequately control the work. Working drawings shall be furnished by the Contractor, as required by the contract documents. When required, the working drawings shall be accompanied by engineering calculations furnished by the Contractor, that substantiate the details of the working drawings.  When certification by a Professional Engineer licensed in the State of Iowa is required, the certification shall be in the appropriate branch of engineering, for the work specified in the contract documents. Working drawings may include shop drawings of fabricated materials, erection plans, falsework plans, cofferdam plans, or other supplemental plans or data. Shop drawings for structures shall show fully detailed dimensions and sizes of all component parts of the structure. Prior to review of working drawings, any work done or material ordered shall be at the Contractor's risk. The Contractor shall understand that the Contracting Authority's review of working drawings shall not constitute validation or endorsement of the Contractor’s means or methods of construction.  The Contracting Authority’s review of shop drawings submitted by the Contractor covers only requirements for strength and arrangement of component parts as relevant to the permanent works. The Contracting Authority assumes no responsibility for errors in dimensions or omissions in the Contractor’s working drawings and assumes the Contractor will use material complying with requirements of the contract documents or, where not specified, those of sound and reasonable quality, and will erect construct the subjects of such working drawings in accordance with recognized standards of first quality work or, when specified, in accordance with standards of the contract documents. If unanticipated and either unusual or complex construction procedures or site conditions occur, the Engineer may require the Contractor to submit such working drawings as, in the judgment of the Engineer, are necessary to satisfactorily control or complete the proposed construction.  Prior to the Engineer’s written acceptance of required working drawings, any work done or material ordered shall be at the Contractor’s risk.

 

B.    Unless specified otherwise in the contract documents, Contractor submittal time will be subject to the specified review time and the Contractor's need based on their schedule for the work.

 

C B.Working drawings shall be submitted in their entirety and shall include complete information as necessary to detail the subject work and satisfy applicable contract requirements.  Submittals Working drawings shall not be subdivided or made in a piecemeal fashion unless approved in writing by the Engineer in advance of the submittal. If subdivided submittals are approved by the Engineer, they shall be made in packages with logical break points (e.g. structural steel units) so the Engineer may make a complete comprehensive review of the subdivided submittal.   For submittals which relate to or depend upon Contractor-generated information not self-contained within the submittal (e.g. bridge girder shop drawings, as they relate to separate bridge bearing shop drawings), any acceptance by the Engineer shall be understood as conditional acceptance subject to change, until such time all relevant information is submitted by the Contractor and reviewed and accepted by the Engineer.

 

D C.Submittals that are required to be revised and resubmitted Revised submittals shall be made as a complete and updated replacement of the previous version.  Abbreviated or piecemeal resubmissions are not acceptable unless approved in writing by the Engineer in advance of the submittal.  Revised submittals shall have the revisions clouded or annotated by the Contractor to designate revisions provide clear identification of all changes. Resubmittals made in accordance with this provision will have a review time in calendar days of half of the review time shown in Table 1105.03-1. Resubmittals that are not in accordance with this provision will be allowed the review time shown in Table 1105.03-1.

 

D.    Unless specified otherwise in Table 1105.03-1 or elsewhere in the contract documents, the Contracting Authority shall be entitled to 30 calendar days for review of working drawing submittals, starting from the date the complete submittal is received from the Contractor.  For submittals which are revised and resubmitted after the initial submittal date, the Contracting Authority shall be entitled to the full review duration starting from the date the last revision is received, except as otherwise specified in Article 1105.03, E.  The Contractor shall account for the allowed review duration when scheduling the work.

 

E.    Resubmittals which are submitted in accordance with Article 1105.03, C, with revisions limited to correction or clarification of details which were included in the previous version of the submittal, shall be allotted review time in calendar days equal to half the review time specified in Article 1105.03, D.  Resubmittals which include new details, or revised details without proper annotation, shall be allotted the full review time specified in Article 1105.03, D.  Combined review time for the original submittal and subsequent revisions shall not be less than the allotted review time for the original submittal.

 

 

E F. Submittals.

 

1.   For projects on the Secondary Road System (non-Primary and Interstate projects), working drawings shall be submitted to the Engineer unless noted otherwise in the contract documents.

 

2.     For Primary and Interstate projects (and when specified for Secondary Road System projects), submittals shall be made via an electronic document management system (Doc Express unless specified otherwise in the contract documents). If noted in the contract documents, submittals shall also be made, to the consultant email address indicated on the contract documents.

a.     The submittal file shall be Portable Document Format (PDF). Minimum resolution of 300 dpi is recommended. Ensure document submitted is legible. Submittal files in other formats (e.g. CAD files) will not be accepted.

b.     Provide project number and submittal description for the document title in Doc Express. The Doc Express submittal will serve as the transmittal log and shall include, by virtue of the user login, the Contractor’s name, address, and telephone number, and the fabricator’s name, address, and telephone number (if applicable). 

c.     Shop drawings submitted electronically via email Doc Express will be tracked, processed, and returned to the Contractor via email Doc Express. Paper copies will not be distributed. 

 

Table 1105.03-1: Review Bureaus for Working Drawings

DESCRIPTION

REVIEW BUREAU

REVIEW TIME

(calendar days)

Falsework for slab bridges

Bridges and Structures

30

Transparent Stay-In-Place Deck Forms

Bridges and Structures

30

Cofferdam design (when required)

Bridges and Structures

30

Reconstruction of substructure (detailed plans for supporting the superstructure)

Bridges and Structures

30

Steel Structures

Bridges and Structures

30

Detail plans for falsework or centering support of steel structures (i.e. erection plans)

Bridges and Structures

30

Steel and aluminum pedestrian hand rails and aesthetic fences

Bridges and Structures

30

Standard support structures for overhead highway signs (i.e. bridge-type trusses, cantilever-type trusses, and bridge mounted supports)

Traffic and Safety(c)

30

Precast concrete (i.e. deck panels, RCB culverts, noise wall panels, arch sections, etc.)

Bridges and Structures

30

Tower lighting

Traffic and Safety

30

Highway lighting

Traffic and Safety

30

Bridge mounted light pole base plates and anchor bolts

Bridges and Structures

30

Highway signing steel breakaway posts

Traffic and Safety

30

Traffic signalization(b)

Traffic and Safety

30

Highway signing - Type A and B signs

Traffic and Safety

30

Reference Location Signs

Traffic and Safety

30

Bridge components

Bridges and Structures

30

Pre-engineered steel truss recreational trail bridge

Bridges and Structures

30

MSE, segmental, and modular block retaining walls (Preliminary and final submittals shall include design calculations, shop drawings, and field construction drawings)

Design

(Soils Design Section)

30 (preliminary)

14 (final)

Soil nail and tie-back retaining walls (Submittal includes final design plans)

Design

(Soils Design Section)

60

Intermediate foundation improvement (IFI) (i.e. stone columns, geopiers, etc.) (Submittal shall include design calculations and field construction drawings)

Design

(Soils Design Section)

30

Removal of box girder bridges

Bridges and Structures

30

Structural erection manual

Bridges and Structures

30

Temporary shoring

Bridges and Structures

30

Temporary sheet pile retaining wall

Bridges and Structures

30


Architectural mock-ups(a)

Bridges and Structures

30

Architectural paving(a)

Bridges and Structures

30

Architectural paint color samples and manufacturer data(a)

Bridges and Structures

30

Architectural concrete texture form liner samples and drawings(a)

Bridges and Structures

30

Architectural concrete sealer samples and manufacturer data(a)

Bridges and Structures

30

Architectural ornamental brick(a)

Bridges and Structures

30

(a) Submittals of physical samples shall be through the Engineer.

(b) Submittal time shall be within 45 calendar days from the date of award of contract.

(c)  Working drawings for nonstandard support structures of overhead highway signs shall be reviewed through the Bridges and Structures Bureau.

 

1105.04    CONFORMITY WITH AND COORDINATION OF THE CONTRACT DOCUMENTS.

 

A.    In case of a discrepancy between contents of the contract documents, the following items listed by descending order shall prevail:

 

1.     Addendum

 

2.     Proposal Form

 

3.     Special Provision

 

4.   Digital Contract Files. Shall apply only when digital files are available and the Contractor uses automated machine control guidance.

 

5.     Plans

 

6.     Standard Bridge Plans, Standard Culvert Plans, and Standard Road Plans

 

7.     Developmental Specifications

 

8.     Supplemental Specifications

 

9.     General Supplemental Specifications

 

10. Standard Specifications

 

11. Materials I.M.

 

12. Notice to Bidders

 

B.   Electronic support files, if available, will be provided prior to letting and are for information only. Should there be a discrepancy between an electronic support file and a contract document, the contract document shall govern.

 

C.    Should there be a discrepancy between figures and drawings on any of the contract documents, the figures shall govern unless they are obviously incorrect.

 

D.    Should there be a discrepancy between a contract document and a document (e.g.: ASTM, AASHTO, MUTCD, etc.) referenced by a contract document, the referenced document shall carry the same hierarchy as the contract document from which it is referenced. Should there be a discrepancy between the contract documents and a referenced document, the contract documents govern unless obviously incorrect.

 

E.    The Contractor shall not take advantage of any apparent error, omission, or discrepancy in the contract documents. The Engineer will be permitted to make such correction in interpretation as may be deemed necessary for the fulfillment of the intent of the contract documents subject to compensation as provided in Articles 1109.03, 1109.04 and 1109.14. Written notice of changes in the contract documents will be given to the Contractor by the Engineer. Field adjustment of digital contract files, if necessary, will be completed by the Engineer.

 

F.     All work performed and all materials furnished shall be in reasonably close conformity with the lines, grades, cross sections, dimensions, and material requirements, including tolerances, shown in the contract documents.

 

G.    If the Engineer finds the material or the finished product in which the material is used is not within reasonably close conformity with the contract documents but that reasonably acceptable work has been produced, the Engineer will then make a determination if the work shall be accepted and remain in place. In this event, the Engineer will document the basis of acceptance by contract modification which will provide for an appropriate adjustment in the contract price for such work or materials as is necessary to conform to the determination based on engineering judgment.

 

H.    If the Engineer finds the material or the finished product in which the material is used or the work performed is not in reasonably close conformity with the contract documents and has resulted in an inferior or unsatisfactory product, the work or material shall be considered unacceptable work and shall be removed and replaced or otherwise corrected by and at the expense of the Contractor.

 

1105.05    SUPERVISION BY CONTRACTOR.

The Contractor or a competent Superintendent must be on the project when construction activities are taking place. This representative must be capable of reading and thoroughly understanding the contract documents and experienced in the type of work being performed. The Superintendent shall supervise, direct, and control the Contractor's operations, personnel, work, and the subcontractor's operations. The Superintendent shall have full authority to execute orders or directions of the Engineer without delay and to promptly supply such materials, equipment, tools, labor, and incidentals as may be required. The Contractor shall give the Engineer written notification of the name of the Superintendent. A copy of the official plans and specifications shall be available on the project site at all times.

 

1105.06    AUTHORITY AND DUTIES OF INSPECTOR.

The Contracting Authority may appoint inspectors to represent the Engineer in the inspection of materials used in and work done under the contract. Such inspection may extend to any part of the work and to preparation or manufacture of materials to be used. The inspector will not be permitted to modify in any way the provisions of the contract documents or to delay the work by failing to inspect materials and work with reasonable promptness. An inspector is placed on the work to keep the Engineer informed as to its progress and the manner in which it is being performed. Results of inspection tests and examinations will be available to the Contractor on an informational basis. Absence or presence of representative test data does not alter the Contractor's responsibility for compliance with the contract documents in accordance with Article 1104.01. The inspector will not act as supervisor or perform other duties for the Contractor, nor improperly interfere with management of the work. The inspector will not be authorized to approve or accept any portion of the work. In case of dispute between the Contractor and inspector as to quality of materials or manner of performing the work, the inspector has authority to reject materials or suspend the work until the question at issue can be decided by the Engineer. Written notice of suspension of work will be given to the Engineer and Contractor by the inspector.

 

1105.07     INSPECTION OF WORK.

 

A.    The Contractor shall furnish the Engineer with every reasonable facility for ascertaining whether the work is being performed in conformance with the contract documents. At any time before acceptance of the work, upon request of the Engineer, the Contractor shall remove or uncover such portions of finished work as the Engineer may direct. After examination has been made, the Contractor shall restore such portions of the work to the standard required by the contract documents.

 

B.    If work thus exposed or examined proves acceptable, the uncovering or removing and replacing of covering, or the restoring of parts removed, will be paid for as extra work, except that no payment will be made for work involved in checking smoothness of pavement surfaces. If work thus exposed and examined proves unacceptable, the Contractor shall replace the defective work in accordance with the specifications. If work thus exposed and examined proves either unacceptable or deficient, the Contractor will be paid only for work as finally accepted.

 

C.    Work done without the Engineer having been afforded ample opportunity to provide suitable inspection, or unauthorized work, may be ordered removed and replaced at the Contractor's expense, or may be excluded from the quantities measured for payment.

 

1105.08     REMOVAL OF DEFECTIVE WORK.

 

A.    Any defective work shall be removed and replaced at the Contractor's expense.

 

B.    Should the Contractor fail or refuse to remove defective work when so ordered by the Engineer, the Engineer has authority to order the Contractor to suspend further operations, and may withhold payment on estimates until such defective work has been removed and replaced in accordance with the contract documents. Continued failure or refusal on the part of the Contractor to correct defective work promptly will be sufficient cause for the Contracting Authority to declare the contract in default and to complete the work in accordance with Article 1108.11.

 

1105.09     UNAUTHORIZED WORK.

Unauthorized work or work done in excess of that provided by the lines and grades shown in the contract documents or as given by the Engineer will not be paid for.

 

1105.10     FINAL INSPECTION.

Upon notification by the Contractor or the Contractor's authorized representative that the work is completed, the Engineer shall make prompt final inspection of each item of work included in the contract. If the work is found not to be in accordance with the contract documents, the Contractor will be advised as to the particular defects to be remedied.

 

1105.11     RESTRICTIONS ON MOVING AND USE OF HEAVY EQUIPMENT.

The following restrictions shall apply to the moving and use of heavy equipment:

 

A.    Movement of equipment to and from the project shall be in compliance with the laws governing the operation of vehicles on the highways of Iowa. Movement and operation of equipment over completed portions of pavements, HMA surfaces, base courses, and structures which are a part of the project shall be with legal axle loads, except as modified in this article.

 

B.    In the case of earthwork and shouldering to be done in connection with either rigid or flexible pavement or pavement widening and resurfacing, earth moving equipment shall not be operated or driven on or across the pavement, except as authorized by the Engineer at designated equipment crossings.

 

When equipment crossings are specifically permitted, the Contractor shall designate before use the location and number of equipment crossings to be used. The location of all equipment crossings shall be subject to the approval of the Engineer. The Engineer will not approve equipment crossings in areas of limited sight distance or near structures or railroad crossings or at any other location which will place safety of the traveling public in jeopardy. At these equipment crossings, equipment having axle loads greater than the maximum permitted by law may be used.

 

Equipment crossings shall be 30 feet in width measured along the center line of the road to be crossed and shall not be closer than 300 feet to each other.

 

Within the prescribed limits, the Contractor may operate hauling equipment on the surface of the pavement or on a hauling bridge constructed by the Contractor.

 

If an equipment crossing is used, the existing driving surface on the through road shall be restored at the end of each day's operation to safely serve traffic at expected speeds. The Contractor may install pavement protection at equipment crossings to reduce the surface restoration at the end of each day's operation.

 

For each equipment crossing used, the Contractor shall, at the Engineer's option, either replace the pavement or pay the Contracting Authority at the rate of $7,500 on the basis of a two lane pavement. The Contractor will not be billed for crossings located within areas designed for removal of pavement after cross hauling is completed as long as the pavement is not damaged by the cross hauling.

 

If a hauling bridge is used, it shall support loaded hauling equipment with no contact with the pavement surface and will be subject to the Engineers approval. When a hauling bridge is used, no pavement replacement or payment to the Contracting Authority will be required.

 

Pavement protection installations and hauling bridges shall accommodate two lanes of public traffic. They shall be removed from the through road at the close of each day's operations.

 

C.    Drag lines, cranes, or power shovels shall not be operated with any part of the machine resting upon a pavement, HMA surface, or base course except with approval of the Engineer and in accordance with restrictions in that approval.

 

D.    For structures, the following equipment and material loads shall apply:

 

1.     Only vehicles and equipment with legal load axle configuration will be permitted on structures unless specifically allowed by the contract documents or approved by the Engineer.

 

2.     Vehicles and equipment will be subject to weight restrictions according to the posted limits.

 

3.     All loads in spans where critical or damaged members, as indicated in the contract documents or identified by the Engineer, are being repaired or replaced shall be subject to the approval of the Engineer.

 

4.     Material loads stored on the structure shall be limited to a maximum weight of 20 tons. Distribution of load shall be governed by the following:

a.     If the material load is greater than 200 pounds per square foot and less than 500 pounds per square foot, the loaded area will be restricted to an area 5 feet by 10 feet (50 square feet) with a clear spacing of 15 feet between loaded areas.

b.     If the material load is less than or equal to 200 pounds per square foot, the loaded area is only restricted by the 20 ton maximum.

 

5.     Construction vehicles and equipment not involved with the loading and unloading of stored material shall be restricted from operating within 10 feet of the area where the material is stored.

 

6.    All vehicle, equipment, and material loads exceeding the limitations as stated above shall be subject to the Engineer’s review and approval. The Contractor shall submit all details, calculations, and assumptions necessary to determine that the structure is capable of supporting the proposed loading. Unless waived by the Engineer, the calculations shall be certified by a Professional Engineer licensed to practice engineering in the State of Iowa.

 

The above submittal requirements shall also apply to cranes or other construction equipment when:

a.     Other components are added resulting in overall weight greater than legally allowed or granted by special permit.

b.    The operational weight including construction loads is greater than legally allowed or granted by special permit.

c.    Load distribution is altered during operation due to the use of outriggers or other devices.

 

E.    Under no conditions shall machines equipped with metal lugs or similar projections on the treads be operated on the surface of a pavement, HMA surface, base course, or structures.

 

F.     For building shoulders on completed pavements of any type, the maximum axle load used for equipment operating on pavement shall not exceed the legal axle load.

 

G.    Crawler type equipment shall not be moved on or off a pavement or base course except at places where the compacted earth adjacent to slab is at least 2 inches higher than the surface of the pavement or base course. When heavy, crawler type equipment is moved on or off the edge of a pavement or base course, an adequate timber approach shall be built at the edge of slab to prevent overloading or otherwise damaging the edge of the slab.

 

H.    Compacting equipment having axle loads greater than 20,000 pounds may be used on the work under the following provisions:

 

1.     The equipment shall be transported to and from the work and across the bridges on the work in compliance with laws of the State of Iowa.

 

2.     For compaction of subbase, the weight of the equipment used shall not be greater than that of compaction equipment used in correction of the roadbed for grade and cross section.

 

3.     For compaction of base course, the weight of the equipment used shall not be greater than the weight of the equipment used in compaction of the subbase on which the base is placed.

 

4.     For compaction of surface courses, the weight of the equipment shall not be greater than that of equipment used in compaction of the base on which the surface course is placed.

 

I.      For grading or any other type of work, no equipment having an axle load greater than 50,000 pounds shall be operated over a culvert except as may be authorized by the Engineer.

 

1105.12     TEMPORARY PRIMARY ROAD HAUL ROADS.

 

A.    For Primary Road projects, the Department may designate any Secondary Road or city street, excluding officially designated temporary Primary Road detours, as a temporary Primary Road haul road, over which materials from any source are to be hauled, such as those listed below:

 

1.     Soil for embankments or shouldering;

 

2.     Sand, gravel, and crushed stone for base and subbase courses;

 

3.     Roadway paving aggregates prior to mixing;

 

4.     Granular surfacing or backfill;

 

5.     Mixed HMA or PCC for paving, transported from the plant to the work site;

 

6.     Broken or milled pavement.

 

B.    Designation of temporary Primary Road haul roads shall be as follows:

 

1.     When materials such as those listed, in an amount greater than 5000 tons, are to be transported to the work by truck, and when requested by the Contractor, or on its own initiative, the Department will designate a temporary Primary Road haul road. In making such designation, the Department will only consider routes which are physically capable for such use. In addition, the Department will consider if the route submitted by the Contractor is practical and feasible regarding length of haul, road conditions, traffic, and maximum utilization of the Primary Road System. The designation will include a separate return route from the project if requested by the Contractor when granular surfaced roads are to be used for the return route. If a separate return route is not requested by the Contractor, it will be designated by the Contracting Authority.

 

2.     The Department reserves the right to designate as a temporary Primary Road haul road a route other than a route selected by the Contractor which is physically capable for such use; in this case, haul in excess of the route selected by the Contractor will be paid for by the Department. The Department will not designate, as a temporary Primary Road haul road, roads normally serving primarily as access to a regularly operated commercial source.

 

3.     When temporary Primary Road haul roads are required, the Contractor shall submit the suggested haul route or routes to the Department within 14 calendar days after the award. Haul route requests shall be submitted to the Engineer. These are to be the most reasonable and practical route or routes. They shall be suitable for use as the haul road or haul roads. In evaluating the feasibility of haul routes, the Contractor shall contact the appropriate local jurisdictions, prior to submitting the haul road request. Roads or bridges with load restrictions and low structural values will not be considered as feasible routes, physically capable of use by the Contractor. If the Contractor fails to provide haul road information within the time allowed, the Department will have the right to establish a route without increased compensation to the Contractor.

 

C.    Primary Roads and temporary Primary Road haul roads for the project shall be used for delivery of materials for which routes are designated.

 

D.    Prior to any revocation by the Department of the temporary Primary Road haul road designation, The Department will comply with Iowa Code 313.28 and 313.29. If restorative work is ordered to be done by the Contractor, payment will be made as extra work in accordance with Article 1109.03.

 

1107.18     environmental protection.

 

1105.14     VALUE ENGINEERING PROPOSAL.

 

A.    The Contractor may submit written Value Engineering (VE) Proposals to the Engineer, for changing the plans, specifications, or other contract requirements. The purpose of this provision is to encourage the Contractor to suggest alternative lower cost or more efficient construction and to share with the Contractor any cost savings. The changes shall not impair the essential functions or characteristics of the project, including but not limited to service life, economy of operation, ease of maintenance, desired appearance, or design and safety standards.

 

B.    VE Proposals shall contain the following information:

 

1.     Existing requirements and proposed changes;

 

2.     Contract requirements that must be changed if the VE proposal is adopted;

 

3.     A detailed cost estimate of performing the work as stipulated and as proposed;

 

4.     The time within which the Engineer must make a decision thereon;

 

5.     The items of work affected by the proposed changes, including quantity variations;

 

6.     A statement that the VE proposal is submitted pursuant to the provisions of Article 1105.14.

 

C.    The provisions of this article do not require the Engineer to consider any VE proposal that is submitted. Proposed changes that involve the basic design of a bridge or pavement type, or involve the use of mechanical dowel bar inserters will not be considered an acceptable incentive proposal.

 

D.    If a VE proposal is similar to a change in the contract documents under consideration by the Contracting Authority for the project at the time the VE proposal is submitted, or if the VE proposal is based on or similar to standard specifications, special provisions, or plans adopted by the Contracting Authority, the Engineer will not accept the VE proposal.

 

E.    The Contractor shall continue to perform the work in accordance with contract requirements until a change order incorporating the VE proposal has been processed. If a change order has not been processed by the date on which the Contractor's VE proposal specifies that a decision thereon should be made, or such other date as the Contractor may subsequently have specified in writing, the proposal shall be rejected.

 

F.     The Contracting Authority will not be liable to the Contractor for failure to accept or act upon any VE Proposal submitted or for any delays to the work attributable to any such VE proposal.

 

G.    The Engineer shall be the sole judge of the acceptability of a VE proposal and of the estimated net savings in construction costs from adoption of all or any part of such VE proposal. In determining the estimated net savings, the right is reserved to disregard the contract bid prices if, in the judgment of the Engineer, the prices do not represent a fair measure of the value of work to be performed or to be deleted.

 

H.    The Contracting Authority reserves the right to require the Contractor to share in the Contracting Authority's costs of investigating a VE proposal. Where this condition is imposed, the Contractor shall indicate acceptance in writing, and acceptance may constitute authority for the Contracting Authority to deduct up to 50% of the investigation costs from any money due to the Contractor resulting from the change.

 

I.      If the Contractor's VE proposal is accepted in whole or in part, such acceptance will be by change order. The change order will incorporate the changes in the contract documents which are necessary to permit the VE Proposal to be put into effect, and will include any conditions upon which the Contracting Authority's approval is based. The change order shall also set forth the estimated net savings in the cost of performing the work attributable to the VE proposal effectuated by the change order, and will further provide that the Contractor be paid 50% of the estimated net savings amount.

 

J.     Acceptance of the VE proposal and performance of the work will not extend the time of completion of the contract, unless specifically provided for in the change order authorizing the proposal.

 

K.    The amount specified to be paid to the Contractor in the change order for a VE proposal shall constitute full compensation to the Contractor for the proposal and performance of the work.

 

L.     The Contracting Authority reserves the right to adopt a VE Proposal for general use on contracts administered by the Contracting Authority when it determines that a VE proposal is suitable for application to other contracts. When an accepted VE proposal is adopted for general use, only the Contractor who first submitted this VE proposal will be eligible for compensation according to this article, and in that case, only on those contracts awarded to the same Contractor prior to submission of the accepted VE proposal and on which such VE proposal is also submitted and accepted. VE proposals identical or similar to previously submitted VE proposals will be eligible for consideration and compensation under provisions of this article if those VE proposals were not adopted for general application to other contracts administered by the Contracting Authority. Subject to the provisions contained herein, the State or any other public agency will have the right to use all or any part of any submitted VE proposal without obligation or compensation of any kind to the Contractor.

 

M.    The Contractor is encouraged to include the provisions of this article in contracts with subcontractors. All VE proposals by subcontractors shall be submitted by the prime contractor.

 

1105.15    CONSTRUCTION STAKES.

 

A.    Minimum standards for Construction Survey provided by the Engineer will meet the requirements of Section 2526. The Engineer will set the necessary center line, slope, and grade stakes promptly upon notification by the Contractor that stakes are needed.

 

B.    For all structures, the Engineer will set stakes for roadway center line and such other stakes as are necessary to establish the location, elevation, and alignment of the structure. If requested by the Contractor, the Engineer will furnish stakes determining the center line of piers or pedestals, the faces of abutments, and angles of the wings or retaining walls. When these stakes or lines are given by the Engineer, the Contracting Authority will be responsible for the correctness thereof, and the Contractor shall be responsible for their proper use, interpretation, and preservation.

 

C.    The Contracting Authority will not be responsible for delays due to lack of grade or line stakes unless the Contractor has given the Engineer a 24 hour written notice that such stakes will be needed and the Contractor's work is being conducted in a satisfactory manner and at the specified rate of progress.

 

D.    The Contractor shall be responsible for the preservation of stakes and marks. If in the opinion of the Engineer any of the survey stakes or marks have been carelessly or willfully destroyed or disturbed by the Contractor, the cost of replacing them will be charged against the Contractor.

 

1105.16    AUTOMATED MACHINE GUIDANCE.

 

A.    Contractor may use equipment with AMG that results in meeting the same accuracy requirements as conventional construction as detailed in the Standard Specifications.

 

B.    Use this section in conjunction with Section 2526 unless construction survey is being provided by the Engineer.

 

C.    Electronic files.

 

1.     Available electronic files will be provided by the Contracting Authority with the Proposal Form. This information is available at the Office of Contracts’ website.

 

2.     Convert electronic data provided by the Contracting Authority into the format required by AMG system. Files made available will be in a generic format. For naming conventions and file formats refer to Office of Design’s online design manual. Note that additional files, such as storm sewer design files, may be included in the original design software format. Files provided may include: 

a.     CAD Files: Primary CADD (Computer Aided Design and Drafting) design file that may include:

·         CADD cross section files.

·         CADD Right of Way file.

·         CADD Topography files.

·         3D Design break line files in an industry standard format.

b.     Machine Control Surface Model Files (including topsoil placement where required on the plans): Documentation file describing all of surface models, in LandXML format. Areas where a surface model is not provided, Contractor may, at no additional cost to Contracting Authority, develop required surface models to facilitate AMG. 

c.     Alignment Data Files: Documentation file describing alignment information both horizontal and vertical, in LandXML format.

 

3.     For PCC overlays, compute an estimated quantity of overlay concrete based on existing pavement profile and the electronic model. This quantity will serve as the estimated concrete quantity for the project and must be approved by the Engineer prior to start of construction.

 

4.     For full-depth paving projects, provide a digital terrain model (DTM) of subgrade surface.

 

5.     For paving projects, provide profiles and alignments and/or 3D polylines at all breakpoints in LandXML format for shoulder and pavement edges as well as the pavement centerline based on project alignments and elevations.

 

6.     No guarantee is made that the data systems used by the Engineer will be directly compatible with the systems the Contractor uses.

 

7.     Electronic information shall not be considered a representation of actual conditions to be encountered during construction. Providing the Contractor this information does not relieve the Contractor from the responsibility of making an investigation of conditions to be encountered, including but not limited to site visits, and basing the bid on information obtained from these investigations and professional interpretations and judgment. Contractor assumes the risk of error if the information is used for any purposes for which the information was not intended. Assumptions the Contractor makes from this electronic information or manipulation of the electronic information is at their risk.

 

8.     Engineer may perform spot checks of the machine control results, surveying calculations, records, field procedures, and actual staking. If the Engineer determines the work is not being performed in a manner assures accurate results, the Engineer may order such work to be redone, to the requirements of the contract documents, at no additional cost to the Contracting Authority.

 

D.    Additional Contracting Authority Responsibilities.

 

1.     For new construction, Engineer will set initial horizontal and vertical control points in the field for the project as indicated in the contract documents. For reconstruction or PCC overlays, Engineer will furnish information on existing horizontal and vertical control points.

 

2.     Engineer will provide project specific localized coordinate system if required. The control information utilized in establishing the localized coordinate system, specifically rotation, scaling, and translation may be requested from the Engineer.

 

3.     For paving, Engineer will review and approve proposed surface model within two weeks following receipt of the model.

 

4.     The Engineer will resolve discrepancies in coordinate data between the plans and field.

 

E.   Additional Contractor Responsibilities.

 

1.     Provide a rover, readily available for Engineer to use jointly with the Contractor, during duration of contract.

 

2.     Provide Engineer training as needed on Contractor’s AMG systems.

 

3.     Contractor bears all costs, including but not limited to cost of actual reconstruction of work that may be incurred due to errors in application of AMG techniques. Grade elevation errors, rework resulting from errors or failures of AMG system, and associated quantity adjustments resulting from Contractor’s activities are at no cost to Contracting Authority. Delays due to late submittals or satellite reception of signals to operate AMG system will not result in adjustment to contract unit prices or justification for granting contract extensions.

 

4.     Check and recalibrate, if necessary, AMG system at beginning of each work day.

 

5.     At least one week prior to preconstruction conference, submit to Engineer for review a written AMG work plan which includes the following:

·         Equipment type,

·         Control software manufacturer and version,

·         Proposed location of local GPS base station for broadcasting differential correction data to rover units, and

·         Proposed locations where AMG will be used. Provide minimum of 30 calendar days notice when there are changes to proposed AMG locations that will require additional construction staking by Contracting Authority. Contractor may perform this additional staking at no additional cost to Contracting Authority.

 

1105.17     Subsoil Tillage.

Prior to placement of topsoil and/or stabilizing crop seeding, perform subsoil tillage to an average depth of 16 to 20 inches on stockpile areas, haul roads, and areas used for storage of equipment. Till at 3 foot maximum centers and at right angles to finished slope.

 

Equip tillage equipment with arrowhead type shoe providing lateral displacement and limit movement of subsoil to the surface. Obtain Engineer’s approval for equipment.

 

It is intended that following subsoil tillage, the area remain in a loosened condition. Additional compaction or operation of heavy equipment, other than that required for topsoil placement and shaping, will not be allowed on areas tilled.

 

This work shall be considered incidental to other work on the project and will not be paid for separately.

 

1105.18     Topsoil on Haul Road.

Before placing a construction haul road, strip topsoil from within proposed haul road footprint to a depth of 8 inches and stockpile. After haul road has been removed, prepare disturbed area according to Article 1105.17, and place topsoil over disturbed area to a minimum depth of 4 inches.

 

This work shall be considered incidental to Mobilization and will not be paid for separately.